FIDIC 99 版中英文

FEDIC合同 新红皮书部分 中英文对照

通用条件

General Conditions

1 一般规定

1. General Provisions

1.1定义

1.1 Definitions

在包括专用条件和本通用条件的合同条件（“本合同条件”）中，以下措辞和用语的含义如下所述。除非上下文中另有要求，指当事人和当事各方的词包括公司和其它法律实体。

In the Conditions of Contract ("these Conditions"), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and other legal entities, except where the context requires otherwise.

1.1.1 合同

1.1.1 The Contract

1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。

1.1.1.1 "Contract" means the Contract Agreement, the Letter of Acceptance, the Letter of Tender, these Conditions, the Specification, the Drawings, the Schedules, and the further documents (if any) which are listed in the Contract Agreement or in the Letter of Acceptance.

1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。

1.1.1.2 "Contract Agreement" means the contract agreement (if any) referred to in Sub-Clause 1.6

[Contract Agreement].

1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函，包括其后所附的备忘录(由合同各方达成并签定的协议构成)。在没有此中标函的情况下，“中标函”一词就指合同协议书，颁发或接收中标函的日期就指双方签订合同协议书的日期。

1.1.1.3 "Letter of Acceptance" means the letter of formal acceptance, signed by the Employer, of the Letter of Tender, including any annexed memoranda comprising agreements between and signed by

both Parties. If there is no such letter of acceptance, the expression "Letter of Acceptance" means the Contract Agreement and the date of issuing or receiving the Letter of Acceptance means the date of signing the Contract Agreement.

1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件，由承包商填写，包括已签字的对雇主的工程报价。

1.1.1.4 "Letter of Tender" means the document entitled letter of tender, which was completed by the Contractor and includes the signed offer to the Employer for the Works.

1.1.1.5“规范(Specification)”指合同中名称为规范的文件，及根据合同规定对规范的增加和修改。此文件具体描述了工程。

1.1.1.5 "Specification" means the document entitled specification, as included in the Contract, and any additions and modifications to the specification in accordance with the Contract. Such document specifies the Works.

1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸，及由雇主(或代表)根据合同颁发的对图纸的增加和修改。

1.1.1.6 "Drawings" means the drawings of the Works, as included in the Contract, and any additional and modified drawings issued by (or on behalf of, the Employer in accordance with the Contract.

1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件，由承包商填写并随投标函提交。此文件可能包括工程量表、数据、列表、及费率和/或单价表。

1.1.1.7 "Schedules" means the document(s) entitled schedules, completed by the Contractor and submitted with the Letter of Tender, as included in the Contract. Such document may include the Bill of Quantities, data, lists, and schedules of rates and/or prices

1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。

1.1.1.8 "Tender" means the Letter of Tender and all other documents which the Contractor submitted with the Letter of Tender, as included in the Contract.

1.1.1.9“投标函附录(Appendix to Tender)”指名称为投标函附录并已填写完毕的文件，附于投标函之后并构成投标函的一部分。

1.1.1.9 "Appendix to Tender" means the completed pages entitled appendix to tender which are appended to and form part of the Letter of Tender.

1.1.1.10 “工程量表(Bill of Quantities)”和“计日工计划(Daywork Schedule)”指资料表中如此命名的文件(如有时)。

1.1.1.10 "Bill of Quantities" and "Day work Schedule" mean the documents so named (if any) which are comprised in the Schedules.

1.1.2 当事各方和当事人

1.1.2Parties and Persons

1.1.2.1“一方(Party)”指雇主或承包商(根据上下文而定)。

1.1.2.1 "Party" means the Employer or the Contractor, as the context requires.

1.1.2.2“雇主(Employer)”指在投标函附录中指定为雇主的当事人或此当事人的合法继承人。

1.1.2.2 "Employer" means the person named as employer in the Appendix to Tender and the legal successors in title to this person.

1.1.2.3“承包商(Contractor)”指在雇主收到的投标函中指明为承包商的当事人(一个或多个)及其合法继承人。

1.1.2.3 "Contractor" means the person(s) named as contractor in the Letter of Tender accepted by the Employer and the legal successors in title to this person(s).

1.1.2.4“工程师(Engineer)”指雇主为合同之目的指定作为工程师工作并在投标函附录中指明的人员，或由雇主按照第3.4款【工程师的撤换】随时指定并通知承包商的其他人员。

1.1.2.4 "Engineer" means the person appointed by the Employer to act as the Engineer for the purposes of the Contract and named in the Appendix to Tender, or other person appointed from time to time by the Employer and noted to the Contractor under Sub-Clause 3.4 [Replacement of the Engineer].

1.1.2.5“承包商的代表(Contractor’s Representitive)”指承包商在合同中指定的或由承包商按照第

4.3款【承包商的代表】随时指定的代表承包商的人员。

1.1.2.5 "Contractor´s Representative" means the person named by the Contractor in the Contract or appointed from time to time by the Contractor under Sub-Clause 4.3 [Contractor´s Representative], who acts on behalf of the Contractor.

1.1.2.6“雇主的人员”指工程师，第3.2款【工程师的授权】中所指的工程师助理以及所有其他职员、劳工和工程师或雇主的其他雇员；以及所有其他由雇主或工程师作为雇主的人员通知

给承包商的人员。

1.1.2.6 "Employer´s Personnel" means the Engineer, the assistants referred to in Sub-Clause 3.2

[Delegation by the Engineer] and all other staff, labour and other employees of the Engineer and of the Employer; and any other personnel notified to the Contractor, by the Employer or the Engineer, as Employer´s Personnel.

1.1.2.7“承包商的人员”指承包商的代表和所有承包商在现场使用的人员，包括职员、劳工和承包商及各分包商的其他雇员；以及其他所有帮助承包商实施工程的人员。

1.1.2.7 "Contractor´s Personnel" means the Contractor´s Representative and all personnel whom the Contractor utilises on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor; and any other personnel assisting the Contractor in the execution of the Works.

1.1.2.8“分包商”指合同中指明为分包商的所有人员，或为部分工程指定为分包商的人员；及所有上述人员的合法继承人。

1.1.2.8 "Subcontractor" means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.

1.1.2.9“争端裁决委员会”指合同中如此命名的一个或三个当事人，或按照第20.2款【争端裁决委员会的委任】或按照第20.3款【未能同意争端裁决委员会的委任】指定的其他人员(一个或多个)。

1.1.2.9 "DAB" means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudication Board] or Sub-Clause 20.3 [Failure to Agree Dispute Adjudication Board]

1.1.2.10 “FIDIC”指国际咨询工程师联合会。

1.1.2.10 "FIDIC" means the international federation of consulting Engineers.

1.1.3 日期、检验、期限和完成

1.1.3 Dates, Tests, Periods and Completion

1.1.3.1“基准日期”指提交投标文件截止日前28天的当日。

1.1.3.1 "Base Date" means the date 28 days prior to the latest date for of the Tender

1.1.3.2“开工日期”指按照第8.1款【工程的开工】通知的日期。

1.1.3.2 "Commencement Date" means the date notified under Sub-Clause 8.1 (commencement of works)

1.1.3.3“竣工时间”指在投标函附录中说明的,按照第8.2款【竣工时间】的规定，由开工日期算起到工程或某一区段(视情况而定)完工的日期(包括按照第8.4款【竣工时间的延长】决定的任何延期)。

1.1.3.3 "Time for Completion" means the time for completing the Works or a Section (as the case may be) under Sub-Clause 8.2 [Time for Completion], as stated in the Appendix to Tender (with any extension under Sub Clause 8.4- [Extension of Time for Completion]), calculated from the Commencement Date.

1.1.3.4“竣工检验”指在雇主接收工程或某区段(视情况而定)前按照第9款【竣工检验】进行的检验，此检验可在合同中说明、或由双方协商决定、或以变更的形式被指示进行。

1.1.3.4 "Tests on Completion" means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried. out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Employer.

1.1.3.5“接收证书”指按照第10条【雇主的接收】颁发的证书。

1.1.3.5 "Taking-Over Certificate" means a certificate issued under Clause 10 [Employer´s Taking Over].

1.1.3.6“竣工后的检验”指合同中规定的，在雇主接收了工程或某区段(视情况而定)后，按照特殊应用条款的规定进行的检验(如有时)。

1.1.3.6 "Tests after Completion" means the tests (if any) which are specked in the Contract and which are carried out in accordance with the provisions of the Particular Conditions after the Works or a Section (as the case may be) are taken over by the Employer.

1.1.3.7“缺陷通知期”指根据投标函附录中的规定，从工程或区段按照第10.1款【工程或区段的接收】被证明完工的日期算起，到按照第11.1款【完成扫尾工作和修补缺陷】通知工程或该区段(视情况而定)中的缺陷的期限(包括按照第11.3款【缺陷通知期的延长】决定的任何延期)。

1.1.3.7 "Defects Notification Period" means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 [Completion of Outstanding Work and

Remedying Defects], as stated in the Appendix to Tender (with any extension under Sub-Clause 11.3

[Extension of Defects Notification Period]), calculated from the date on which the Works or Section is completed as certified under Sub-Clause 10.1 [Taking Over of the Works and Sections].

1.1.3.8“履约证书”指按照第11.9款【履约证书】颁发的证书。

1.1.3.8 "Performance Certificate" means the certificate issued under Sub¬ Clause 11.9 [Performance Certificate].

1.1.3.9“日”指一个公历日，而“年”指365天。

1.1.3.9 "day" means a calendar day and "year" means 365 days.

1.1.4 款项与支付

1.1.4 Money and Payments

1.1.4.1“接受的合同款额”指雇主在中标函中对实施、完成和修补工程所接受的金额。

1.1.4.1 "Accepted Contract Amount" means the amount accepted in the Letter of Acceptance for the execution and completion of the Works and the

1.1.4.2“合同价格”指第14.1款【合同价格】中定义的价格，包括根据合同所做的调整。

1.1.4.2 "Contract Price" means the price defined in Sub-Clause 14.1 [The Contract Price], and includes adjustments in accordance with the Contract.

1.1.4.3“费用”指承包商在现场内或现场外正当发生(或将要发生)的所有开支，包括管理费和类似支出，但不包括利润。

1.1.4.3 "Cost" means all expenditure reasonably incurred (or to be incurred) by the Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit.

1.1.4.4“最终支付证书”指按照第14.13款【最终支付证书的颁发】颁发的支付证书。

1.1.4.4 "Final Payment Certificate" means the payment certificate issued under Sub-Clause 14.13

[Issue of Final Payment Certificate].

1.1.4.5“最终报表”指第14.11款【最终支付证书的申请】中定义的报表。

1.1.4.5 "Final Statement" means the statement defined in Sub-Clause 14.11 [Application for Final Payment Certificate].

1.1.4.6“外币”指可用来支付部分(或全部)合同价格的某种货币，但不指当地货币。

1.1.4.6 "Foreign Currency" means a currency in which part (or all) of the Contract Price is payable,

but not the Local Currency.

1.1.4.7“期中支付证书”指根据第14条【合同价格和支付】颁发的付款证书，但不包括最终支付证书。

1.1.4.7 "Interim Payment Certificate" means a payment certificate issued under Clause 14 [Contract Price and Payment], other than the Final Payment Certificate.

1.1.4.8“当地币”指工程所在国的货币。

1.1.4.8 "Local Currency" means the currency of the Country.

1.1.4.9“支付证书”指按照第14条【合同价格和支付】颁发的支付证书。

1.1.4.9 "Payment Certificate" means a payment certificate issued under Clause 14 [ Contract Price and Payment ].

1.1.4.10 “暂定金额”指合同中指明为暂定金额的一笔金额(如有时)，用于按照第13.5款【暂定金额】实施工程的任何部分或提供永久设备、材料和服务的一笔金额(如有时)。

1.1.4.10 "Provisional Sum" means a sum (if any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Materials or services under Sub-Clause 13.5 [Provisional Sums].

1.1.4.11 “保留金”指雇主按照第14.3款【期中支付证书的申请】扣留并按第14.9款【保留金的支付】支付的累计的保留金。

1.1.4.11 "Retention Money" means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 [Application for Interim Payment Certificates] and pays under Sub-Clause 14.9 [Payment of Retention Money].

1.1.4.12 “报表”指承包商按照第14条【合同价格和支付】申请支付证书时作为申请一部分而提交的报表。

1.1.4.12 "Statement" means a statement submitted by the Contractor as part of an application, under Clause 14 [Contract Price and Payment], for a payment certificate.

1.1.5 工程和货物

1.1.5 Works and Goods

1.1.5.1“承包商的设备”指用于实施和完成工程以及修补缺陷所需要的全部机械、仪器、车辆和其它设备。其中不包括临时工程、雇主的设备(如有时)、永久设备、材料和所有其它将构成或

构成永久工程一部分的任何物品。

1.1.5.1 "Contractor´s Equipment" means all apparatus, machinery, vehicles and the remedying of any defects. However, Contractor Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the pavement works.

1.1.5.2“货物”指承包商的设备、材料、永久设备和临时工程，或视情况指其中之一。

1.1.5.2 "Goods" means Contractor´s equipment, Materials, Plant and Temporary Works, or any of them as appropriate.

1.1.5.3“材料”指将构成或构成部分永久工程的各类物品(永久设备除外)，包括由承包商按照合同仅负责供应的材料(如有时)。

1.1.5.3 "Materials,, means things of all kinds (other than Plant) intended to form or forming part of the Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract.

1.1.5.4“永久工程”指将由承包商按照合同实施的永久工程。

1.1.5.4 "Permanent Works" means the permanent works to be executed by the Contractor under the Contract.

1.1.5.5“永久设备”指将构成或构成部分永久工程的机械、仪器和车辆。

1.1.5.5 "Plant" means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works.

1.1.5.6“区段”指投标函附录中指明为区段的部分工程(如有时)。

1.1.5.6 "Section" means apart of the Works specified in the Appendix to Tender as a Section (if any).

1.1.5.7“临时工程”指为了实施和完成永久工程以及修补任何缺陷在现场上所需的各种类型的临时工程(承包商的设备除外)。

1.5.7 "Temporary Works" means all temporary works of every kind (other than Contractor´s Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects.

1.1.5.8“工程”指永久工程和临时工程，或视情况指其中之一。

1.1.5.8 "Works" mean the Permanent Works and the Temporary Works, or either of them as appropriate.

1.1.6 其它定义

1.1.6 Other Definitions

1.1.6.1“承包商的文件”指由承包商按照合同规定提交的计算书、计算机程序及其它软件、图纸、手册、模型、和其它技术性文件(如有时)。

1.1.6.1 "Contractor´s

1.1.6.2“工程所在国”指现场(或大部分现场)所在的国家，永久工程将在此实施。

1.1.6.2 "Country" means the country in which the Site (or most of it) is located, where the Permanent Works are to be executed.

1.1.6.3“雇主的设备”指规范中说明的，在实施工程的过程中，雇主提供给承包商使用的机械、仪器和车辆(如有时)；但不包括尚未被雇主接收的永久设备。

1.1.6.3 "Employer´s Equipment" means the apparatus, machinery and vehicles (if any) made available by the Employer for the use of the Contractor in the execution of the Works, as stated in the Specification; but does not include Plant which has not been taken over by the Employer.

1.1.6.4“不可抗力”如第19条【不可抗力】中所定义。

1.1.6.4 "Force Majeure" is defined in Clause 19 [Force Majeure]

1.1.6.5“法律”指所有国家(或州)的立法、法令、法规和其它法律、任何合法设立的政府机构的规章和章程。

1.1.6.5 "Laws" means all national (or state) legislation, statutes, ordinances and other laws, and regulations and by-laws of any legally constituted public authority.

1.1.6.6“履约保证”指第4.2款【履约保证】中的保证(可能有多份)。

1.1.6.6 "Performance Security" means the security (or securities, if any) under Sub-Clause 4.2

[Performance Security].

1.1.6.7“现场”指永久工程将要实施且永久设备和材料将运达的地点，及其它合同中规定为现场一部分的地点。

1.1.6.7 "Site" means the places where the Permanent Works are to be executed and to which Plant and Materials are to be delivered, and any other places as may be specified in the Contract as forming part of the Site.

1.1.6.8“不可预见”指一个有经验的承包商在提交投标文件那天还不能合理预见的。

1.1.6.8 "Unforeseeable" means not reasonably foreseeable by an experienced contractor by the date for submission of the Tender.

1.1.6.9“变更”指按照第13条【变更和调整】被指示或批准作为变更的对工程的任何变动。

1.1.6.9 "Variation" means any change to the Works, which is instructed or approved as a variation under Clause 13 [Variations and Adjustments].

1.2解释

1.2 Interpretation

在合同中，除非文中另有规定，否则：

In the Contract, except where the context requires otherwise:

（a） 表示阳性、阴性或中性的词包括所有的性别；

(a)

（b） 单数形式的词亦包括复数含义，复数形式的词亦包括单数含义；

(b)

（c）包括“同意”、“批准”或“协议”这些字眼的规定，要求将涉及的协议书面记录下来，且 (c)

（d） “书面的”或“书面地”指手写、打字、印刷或运用电子技术制做，并形成了永久性的记录。 (d) "written" or "in writing" means hand-written, type-written, printed or electronically made, and resulting in a permanent record.

解释本合同条件时，不应考虑旁注和其它标题。

The marginal words and other headings shall not be taken into consideration in the interpretation of these Conditions.

1.3通讯联络

1.3 Communications

在合同条件中，无论何处述及发出或颁发批准、证书、同意、决定、通知和要求，这些通讯联络均应：

Wherever these Conditions provide for the giving or issuing of approvals, certificates, consents, determinations, notices and requests, these communications shall be:

（a） 为书面的，且应派人面交并取得收据，或者邮寄，或由信使送达，或按投标函附录中所

列通过经同意的电子传输系统传输；且

(a) in writing and delivered by hand (against receipt), sent by mail or courier, or transmitted using any of the agreed systems of electronic transmission as stated in the Appendix to Tender; and （b）递交、邮寄或传输到投标函附录中规定的收件人地址。但是：

(b) delivered, sent or transmitted to the address for the recipient´s communications as stated in the Appendix to Tender. However:

（i） 如果收件人发出了更改地址的通知，其后的信件应投送到相应的地址；且

(i) if the recipient gives notice of another address, communications shall thereafter be delivered accordingly; and

（ii）如果收件人在要求批准或同意时没有另做说明，此批准或同意可送达发出要求的地址。 (ii) If the recipient has not stated otherwise when requesting an approval or consent, it may be sent to the address from which the request was issued.

批准、证书、同意及决定不得被无理扣压或拖延。向一方颁发证书时，颁发者应向另一方送交一份复印件。当另一方或工程师向一方发出通知时，应向工程师或另一方送交一份复印件(视情况而定)。

Approvals, certificates, consents and determinations shall not be unreasonably withheld or delayed. When a certificate is issued to a Party, the certifier shall send a copy to the other Party. When a notice is issued to a Party, by the other Parry or the Engineer, a copy shall be sent to the Engineer or the other Party, as the case may be.

1.4法律和语言

1.4 Law and Language

合同应受投标函附录中规定的国家(或其它管辖区域)的法律的制约。

The Contract shall be governed by the law of the country (or other jurisdiction) stated in the Appendix to Tender.

如果合同的任何部分使用一种以上语言编写，从而构成了不同的版本，则以投标函附录中规定的主导语言编写的版本优先。

If there are versions of any part of the Contract which are written in more than one language, the version which is in the ruling language stated in the Appendix to Tender shall prevail.

往来信函应使用投标函附录中规定的语言。如果投标函附录中没有规定，则往来信函应使用编写合同(或大部分合同)的语言。

The language for communications shall be that stated in the Appendix to Tender. If no language is stated there, the language for communications shall be the language in which the Contract (or most of it) is written.

1.5文件的优先次序

1.5 Priority of documents

构成合同的各个文件应被视作互为说明的。为解释之目的，各文件的优先次序如下：

The documents forming the Contract are to be taken as mutually explanatory of one another. For the purposes of interpretation, the priority of the documents shall be in accordance with the following sequence:

（a） 合同协议书(如有时)，

(a) the Contract Agreement (if any),

（b）中标函，

(b) the Letter of Acceptance,

（c）投标函，

(c) the Letter of Tender,

（d）专用条件，

(d) the Particular Conditions,

（e）本通用条件

(e) these General Conditions,

（f） 规范

(f) the Specification,

（g）图纸，和

(g) the Drawings, and

（h）资料表以及其它构成合同一部分的文件。

(h) the Schedules and any other documents forming part of the Contract.

如果在合同文件中发现任何含混或矛盾之处，工程师应颁发任何必要的澄清或指示。

If an ambiguity or discrepancy is found in the documents, the Engineer shall issue any necessary clarification or instruction.

1.6合同协议书

1.6 Contract Agreement

除非双方另有协议，否则双方应在承包商收到中标函后的28天内签订合同协议书。合同协议书应以专用条件后所附的格式为基础。法律规定的与签订合同协议书有关的印花税和其它类似费用(如有时)应由雇主承担。

The Parties shall enter into a Contract Agreement within 28 days after the Contractor receives the Letter of Acceptance, unless they agree otherwise. The Contract Agreement shall be based upon the form annexed to the Particular Conditions. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Contract Agreement shall be borne by the Employer.

1.7转让

1.7 Assignment

任一方都不得转让整个或部分合同或转让根据合同应得的利益或权益。但一方：

Neither Party shall assign the whole or any part of the Contract or any benefit or interest in or under the Contract. However, either Party:

（a）经另一方的事先同意可以转让整个或部分合同，决定权完全在于另一方，及

(a) may assign the whole or any part with the prior agreement of the other Party, at the sole discretion of such other Party, and

（b）可将其按照合同对任何到期或将到期的金额所享有的权利，以银行或金融机构作为受益人，作为抵押转让出去。

(b) may, as security in favour of a bank or financial institution, assign its right to any moneys due, or to become due, under the Contract.

1.8文件的保管和提供

1.8Care and Supply of documents

规范和图纸应由雇主保护和保管。除非合同另有规定，否则雇主应向承包商提供合同及每份后续图纸的两份复印件，承包商可自行复制或要求雇主为其提供更多的复印件，但费用自理。

The Specification and Drawings shall be in the custody and care of the Employer. Unless otherwise stated in the Contract, two copies of the Contract and of each subsequent Drawing shall be supplied to the Contractor, who may make or request further copies at the cost of the Contractor.

在移交给雇主之前，每份承包商的文件都应由承包商来保护和保管。除非合同另有规定，否则承包商应向工程师提供6份承包商的所有文件的复印件。

Each of the Contractor´s documents shall be in the custody and care of the Contractor, unless and until taken over by the Employer. Unless otherwise stated in the Contract, the Contractor shall supply to the Engineer six copies of each of the Contractor´s documents.

承包商应在现场保留一份合同的复印件、规范中列出的所有文件、承包商的文件(如有时)、图纸和变更以及其它按照合同收发的往来信函。雇主的人员有权在任何合理的时间查看和使用所有上述文件。

The Contractor shall keep, on the Site, a copy of the Contract, publications named in the Specification, the Contractor´s documents (if any), the Drawings and Variations and other communications given under the Contract. The Employer´s Personnel shall have the right of access to all these documents at all reasonable times.

如果一方在用于施工的文件中发现了技术性错误或缺陷，应立即向另一方通知此类错误或缺陷。

If a Party becomes aware of an error or defect of a technical nature in a document which was prepared for use in executing the Works, the Party shall promptly give notice to the other Party of such error or defect.

1.9拖延的图纸或指示

1.9 Delayed Drawings or Instructions

当因必要的图纸或指示不能在一合理的特定时间内颁发给承包商，从而可能引起工程延误或中断时，承包商应通知工程师。通知中应包括所必需的图纸或指示的详细内容、应颁发的详细理由和时间，以及如果因图纸或指示迟发可能造成的延误或中断的具体性质和程度。

The Contractor shall give notice to the Engineer whenever the Works are likely to be delayed or disrupted if any necessary drawing or instruction is not issued to the Contractor within a particular time, which shall be reasonable. The notice shall include details of the necessary drawing or

instruction, details of why and by when it should be issued, and details of the nature and amount of the delay or disruption likely to be suffered if it is late.

如果因工程师未能在一合理的、且已在(附有详细证据的)通知中说明的时间内颁发承包商在通知中要求的图纸或指示，而导致承包商延误和(/或)招致费用增加时，承包商应向工程师发出进一步的通知，且按照第20.1款【承包商的索赔】有权获得：

If the Contractor suffers delay and/or incurs Cost as a result of a failure of the Engineer to issue the notified drawing or instruction within a time which is reasonable and is specified in the notice with supporting details, the Contractor shall give a further notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor´s Claims] to:

（a） 根据第8.4款【竣工时间的延长】对任何此类延误的一段延期，如果竣工被拖延或将被拖延；及

(a)an extension of time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4

[Extension of Time for Completion], and

（b）对此费用加上合理利润的支付，此支付应包括在合同价中。

(b)payment of any such Cost plus reasonable profit, which shall be included in the Contract Price. 收到上述进一步的通知后，工程师应按照第3.5款【决定】对这些事项表示批准或作出决定。 After receiving this further notice, the Engineer shall proceed in accordance with Sub¬ Clause 3.5

[Determinations] to agree or determine these matters.

但是，如果工程师未能及时提供图纸或指示是由承包商的错误或延误(包括递交承包商的文件时的错误和延误)引起的，则承包商无权获得上述延期、费用或利润。

However, if and to the extent that the Engineer´s failure was caused by any error or delay by the Contractor, including an error in, or delay in the submission of, any of the Contractor´s documents, the Contractor shall not be entitled to such extension of time, Cost or profit.

1.10雇主使用承包商的文件

1.10 Employer´s Use of Contractor´s documents

在合同双方之间，承包商应对承包商的文件和其它由承包商(或承包商授权的人员)编制的设计文件保留版权和其它知识产权。

As between the Parties ´the Contractor shall retain the copyright and other intellectual property

rights in the Contractor´s documents and other design documents made by (or on behalf of) the Contractor

应认为承包商通过签订合同给予了雇主复印、使用及传输(包括修改和使用对其的修改)承包商的文件的免费使用的许可证，此许可证是无限期的、可转让且非专用的。此许可证应：

The Contractor shall be deemed (by signing the Contract) to give to the Employer a non-terminable transferable non-exclusive royalty-free licence to copy, use and communicate the Contractor´s documents, including making and using modifications of them. This licence shall:

（a） 在工程各有关部分的实际或预期工作期（取较长者）内有效，

(a)apply throughout the actual or intended working life (whichever is longer) of the relevant parts of the Works,

（b） 使任何合法拥有工程有关部分的当事人为完成、操作、维护、改变、调整、修理和拆除工程之目的，复印、使用、传输承包商的文件，且

(b)entitle any person in proper possession of the relevant part of the Works to copy, use and communicate the Contractor´s documents for the purposes of completing, operating, maintaining, altering, adjusting, repairing and demolishing the Works, and

（c） 在承包商的文件采用计算机程序和其它软件形式的情况下，允许其在置于现场及其它合同中许可的地点的计算机(包括由承包商提供的代用计算机)上使用。

(c)in the case of Contractor´s documents which are in the form of computer programs and other software, permit their use on any computer on the Site and other places as envisaged by the Contract, including replacements of any computers supplied by the Contractor.

未经承包商同意，雇主不得因本款规定外的任何目的为第三方复印、使用或传输承包商的文件及其它任何由承包商(或承包商授权的人员)编制的设计文件。

The Contractor´s documents and other design documents made by (or on behalf of) the Contractor shall not, without the Contractor´s consent, be used, copied or communicated to a third party by (or on behalf of) the Employer for purposes other than those permitted under this Sub-Clause.

1.11承包商使用雇主的文件

1.11 Contractor´s Use of Employer´s documents

在合同双方之间，雇主应对规范、图纸和其它由雇主(或雇主授权的人员)编制的设计文件保留

版权和其它知识产权。承包商可为合同之目的，自费复印、使用、及传输上述文件。除非因履行合同而必需，否则不经雇主同意，承包商不得为第三方复印、使用、或传输上述文件。 As between the Parties, the Employer shall retain the copyright and other intellectual property rights in the Specification, the Drawings and other documents made by (or on behalf of) the Employer. The Contractor may, at his cost, copy, use, and obtain communication of these documents for the purposes of the Contract. They shall not, without the Employer´s consent, be copied, used or communicated to a third party by the Contractor, except as necessary for the purposes of the Contract.

1.12保密事项

1.12 Confidential Details

为证实承包商是否遵守合同，他应按照工程师的合理要求透露其要求的保密事项和其它情况。 The Contractor shall disclose all such confidential and other information as the Engineer may reasonably require in order to verify the Contractor´s compliance with the Contract.

1.13遵守法律

1.13 Compliance with Laws

除非在专用条件中另有说明，履行合同时，承包商应遵守适用的法律的规定：

The Contractor shall, in performing the Contract, comply with applicable Laws. Unless otherwise sated in the Particular conditions:

（a） 雇主应已经(或将要)获得永久工程的规划、分区和其它类似许可，及规范中说明已经(或将要)由雇主取得的其它许可；雇主应保障承包商不受其未得到上述许可的后果的侵害；且 (a)the Employer shall have obtained (or shall obtain) the planning, zoning or similar permission for the Permanent Works, and any other permissions described in the Specification as having been (or being) obtained by the Employer; and the Employer shall indemnify and hold the Contractor harmless against and from the consequences of any failure to do so; and

（b） 对于法律中要求的与实施、完成工程和修补缺陷有关的各项事宜，应由承包商发出通知、支付税款、关税和费用，并获得所有的许可、许可证和批准；承包商应保障雇主免遭其未做到上述要求的后果的损失。

(b)the Contractor shall give all notices, pay all taxes, duties and fees, and obtain all permits, licences

and approvals, as required by the Laws in relation to the execution and completion of the Works and the remedying of any defects; and the Contractor shall indemnify and hold the Employer harmless against and from the consequences of any failure to do so.

1.14共同的与各自的责任

1.14 Joint and Several Liability

如果承包商是由两个或两个以上当事人组成的联营体、联合集团或其它联合团体时：

If the Contractor constitutes (under applicable Laws) a joint venture, consortium or other unincorporated grouping of two or more persons:

（a） 应认为上述当事人应向雇主对合同的履行负共同的与各自的责任；

(a)these persons shall be deemed to be jointly and severally liable to the Employer for the performance of the Contract;

（b）上述当事人应向雇主通知他们的负责人，此负责人有权管理承包商及其中每位成员；且 (b)these persons shall notify the Employer of their leader who shall have authority to bind the Contractor and each of these persons; and

没有雇主的事先同意，承包商不得改变其组成或法律地位。

(c)the Contractor shall not alter its composition or legal status without the prior consent of the Employer.

2 雇主

2. THE EMPLOYER

2.1进入现场的权利

2.1 Right of Access to the Site

雇主应在投标函附录中注明的时间（或各时间段）内给予承包商进入和占用现场所有部分的权利。此类进入和占用权可不为承包商独享。如果合同要求雇主赋予(承包商)对基础、结构、永久设备或通行手段的占用权，则雇主应在规范注明的时间内按照规范中规定的方式履行该职责。但是在收到履约保证之前，雇主可以不给予任何此类权利或占用。

The Employer shall give the Contractor right of access to, and possession of, all parts of the Site within the time (or times) stated in the Appendix to Tender. The right and possession may not be exclusive to the Contractor. If, under the Contract, the Employer is required to give (to the

Contractor) possession of any foundation, structure, plant or means of access, the Employer shall do so in the time and manner stated in the Specification. However, the Employer may withhold any such right or possession until the Performance Security has been received.

如果投标函附录中未注明时间，则雇主应在一合理的时间内给予承包商进入现场和占用现场的权利，此时间应能使承包商可以按照第8.3款【进度计划】提交的进度计划顺利开始施工。 If no such time is stated in the Appendix to Tender, the Employer shall give the Contractor right of access to, and possession of, the Site within such times as may be required to enable the Contractor to proceed in accordance with the programme submitted under Sub-Clause 8.3 [Programme].

如果由于雇主一方未能在规定时间内给予承包商进入现场和占用现场的权利，致使承包商延误了工期和(或)增加了费用，承包商应向工程师发出通知，并依据第20.1款【承包商的索赔】有权：

If the Contractor suffers delay and/or incurs Cost as a result of a failure by the Employer to give any such right or possession within such time, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor´s Claims] to:

(a) 如果竣工已经或将被延误，根据第8.4款【竣工时间的延长】的规定，对所有此类延误获得延长的工期，；以及

(a) an extension of time for any such, delay, if completion is or will be delayed, under Sub-Clause

8.4 [Extension of Time for Completion], and

(b) 获得任何有关费用加上合理利润的支付，并将之加入合同价格。

(b) payment of any such Cost plus reasonable profit, which shall be included in the Contract Price. 在收到此通知后，工程师应按照第3.5款【决定】对此事作出商定或决定。

After receiving this notice, the Engineer shall proceed in accordance with Sub¬ Clause 3.5

[Determinations] to agree or determine these matters.

然而，如果雇主的过失（并且在一定程度上）是由于承包商的某些错误或延误造成的，包括承包商的文件中的错误或提交的延误，则承包商无权要求获得此类延长的工期、费用或利润。 However, if and to the extent that the Employer´s failure was caused by any error or delay by the Contractor, including an error in, or delay in the submission of, any of the Contractor´s documents, the Contractor shall not be entitled to such extension of time, Cost or profit.

2.2许可、执照和批准

2.2 Permits, Licences or Approval

雇主应根据承包商的请求，为以下事宜向承包商提供合理的协助（如果他的地位能够做到），以帮助承包商：

The Employer shall (where he is in a position to do so) provide reasonable assistance to the Contractor at the request of the Contractor:

(a) 获得与合同有关的但不易取得的工程所在国的法律的副本，以及

(a) by obtaining copies of the Laws of the Country which are relevant to the Contract but are not readily available, and

(b) 申请法律所要求的许可、执照或批准，包括

(b) for the Contractor´s applications for any permits, licences or approvals required by the Laws of the Country:

(i) 依据第1.13款【遵守法律】要求承包商必须获得的，

(i)which the Contractor is required to obtain under Sub-Clause 1.13 [Compliance with Laws], (ii) 为了货物的运送，包括清关所需的，以及

(ii)for the delivery of Goods, including clearance through customs, and

(iii) 当承包商的设备运离现场而出口时所需的。

(iii)for the export of Contractor´s Equipment when it is removed from the

2.3雇主的人员

2.3 Employer´s Personnel

雇主有责任保证现场的雇主的人员和雇主的其他承包商：

The Employer shall be responsible for ensuring that the Employer´s Personnel and the Employer´s other contractors on the Site:

(a) 依照第4.6款【合作】为承包商的工作提供合作，以及

(a) co-operate with the Contractor´s efforts under Sub-Clause 4.6 [Co-operation], and

(b) 采取类似于承包商按照第4.8款【安全措施】(a)、(b)和(c)段和第4.18款【环境保护】的要求而应采取的措施。

(b) take actions similar to those which the Contractor is required to take under sub¬paragraphs (a),

(b) and (c) of Sub-Clause 4.8 [Safety Procedures] and under Sub-Clause 4.18 [Protection of the Environment].

2.4雇主的资金安排

2.4 Employer´s Financial Arrangements

在接到承包商的请求后，雇主应在28天内提供合理的证据，表明他已作出了资金安排，并将一直坚持实施这种安排，此安排能够使雇主按照第14条【合同价格和支付】的规定支付合同价格（按照当时的估算值）的款额。如果雇主欲对其资金安排做出任何实质性变更，雇主应向承包商发出通知并提供详细资料。

The Employer shall submit. within 28 days after receiving any request from the Contractor, reasonable evidence that financial arrangements have been made and are being maintained which will enable the Employer to pay the Contract Price (as estimated at that time) in accordance with Clause 14 [Contract Price and Payment]. If the Employer intends to make any material change to his financial arrangements, the Employer shall give notice to the Contractor with detailed particulars.

2.5雇主的索赔

2.5Employer´s Claims

如果雇主认为按照任何合同条件或其它与合同有关的条款规定他有权获得支付和（或）缺陷通知期的延长，则雇主或工程师应向承包商发出通知并说明细节。但对于按照第4.19款【电、水、气】、第4.20款【雇主的设备及免费提供的材料】的规定，承包商应支付的款额或其它因承包商要求某些服务而应支付的款额，则无须发出通知。

If the Employer considers himself to be entitled to any payment under any Clause of these Conditions or otherwise in connection with the Contract, and/or to any extension of the Defects Notification Period, the Employer or the Engineer shall give notice and particulars to the Contractor. However, notice is not required for payments due under Sub-Clause 4.19 [Electricity, Water and Gas], under Sub-Clause 4.20 [Employer´s Equipment and Free-Issue Material], or

当雇主意识到某事件或情况可能导致索赔时应尽快地发出通知。涉及任何延期的通知应在相关缺陷通知期期满前发出。

The notice shall be given as soon as practicable after the Employer became aware of the event or circumstances giving rise to the claim. A notice relating to any extension of the Defects Notification

本文来源：https://www.bwwdw.com/article/7fmj.html